Installation Notice

DOVE COMMUNICATIONS, INC.

Installation Notice — Mechanics Lien & Cancellation Disclosures

Required for installation projects performed by Dove in California • Version 1.0 • February 1, 2026

Contractor	Dove Communications, Inc.
CSLB License Number	#715876 — C7 Low Voltage Systems
BSIS ACO License	8206
BSIS Qualified Manager	Ofir Yungman │ BSIS QM #8030 │ Current
Business Address	1374 E. 41st St., Los Angeles, CA 90011
Phone / Email	(213) 234-2500 │ service@dovecommunications.com
Document Version	1.0 │ Effective Date: February 1, 2026
Relationship to MSA	This Installation Notice is issued per the Master Services Agreement (MSA) and applicable Quote. Operational installation terms (site requirements, hardware substitution, NDAA, prevailing wage, warranty, working hours) are set forth in MSA §10A, §10B, §22.4, and §7.18. This Notice provides the mechanics lien and cancellation disclosures required by California law for installation projects.

CALIFORNIA CONTRACTORS STATE LICENSE BOARD (CSLB) INFORMATION: CSLB is the state consumer protection agency that licenses and regulates construction contractors. Contact CSLB for information about the licensed contractor you are considering, including information about disclosable complaints, disciplinary actions, and civil judgments that are reported to CSLB. Use only licensed contractors. If you file a complaint against a licensed contractor within the legal deadline (usually four years), CSLB has authority to investigate the complaint. Contact CSLB at: P.O. Box 26000, Sacramento, CA 95826 | (800) 321-CSLB (2752) | www.cslb.ca.gov

SECTION 1 — PROJECT IDENTIFICATION

Project / Quote Number
Project Description
Installation Address
Approximate Start Date
Approximate Completion Date
Significant Materials / Equipment
Labor Description

SECTION 2 — CONTRACT PRICE AND PAYMENT SCHEDULE

The total contract price and payment schedule are as stated in the applicable Quote. The following payment structure applies unless the Quote states otherwise:

• 25% due upon acceptance and signing of this Installation Notice and the applicable Quote;

• 60% due upon delivery of equipment to the installation site or commencement of installation, whichever occurs first;

• Remaining balance due upon substantial completion of installation work.

CALIFORNIA RESIDENTIAL PROJECTS — DOWN PAYMENT LIMIT: For projects at a residential property, California law limits the initial down payment to the lesser of ten percent (10%) of the total contract price or $1,000, whichever is less. The payment schedule above applies to commercial projects. If this project is at a residential property, the applicable Quote must be reviewed for compliance with B&P §7159 down payment restrictions.

SECTION 3 — MECHANICS LIEN NOTICE

NOTICE TO PROPERTY OWNER

If bills are not paid in full for labor, services, equipment, or materials furnished or to be furnished, a mechanics lien leading to the loss, through court foreclosure proceedings, of all or part of your property being so improved may be placed against the property even though you have paid your contractor in full.

You may wish to protect yourself against this consequence by (1) requiring your contractor to furnish a signed release by the person or firm giving you this notice before making payment to your contractor, or (2) any other method or device that is appropriate under the circumstances.

Other than residential homeowners who obtain a payment bond, owners on private works may stop the obligation of an owner to pay a claimant who is not contracted with the owner by recording a Notice of Completion after the work of improvement is complete.

Dove will provide a 20-Day Preliminary Notice for construction-related work in California to preserve its mechanics lien rights. Client must provide current ownership and lender information upon request.

SECTION 4 — THREE-DAY RIGHT TO CANCEL

NOTICE OF YOUR RIGHT TO CANCEL

You may cancel this contract within THREE (3) BUSINESS DAYS after the date you received a signed and dated copy of this contract that includes this notice, or within FIVE (5) BUSINESS DAYS if you are 65 years of age or older, unless this is a service and repair contract for $750 or less.

To cancel, email, mail, fax, or deliver a written notice to Dove Communications, Inc. at the address or email below by midnight of the deadline. Include your name, address, and the date you received this contract.

Cancel By Email	service@dovecommunications.com
Cancel By Mail	Dove Communications, Inc., 1374 E. 41st St., Los Angeles, CA 90011
Cancel By Fax	(213) 234-2500

DETACHABLE CANCELLATION FORM — NOTICE OF CANCELLATION: To cancel this contract, fill in and deliver this form: I, [CLIENT NAME], cancel the contract dated _______ between me and Dove Communications, Inc. for installation at [ADDRESS]. Client Signature: _________________ Date: _________

SECTION 5 — SIGNATURES

By signing below, both parties agree to the terms of this Installation Notice, including the mechanics lien notice, three-day right to cancel, and payment schedule above. The Master Services Agreement and applicable Quote govern all other operational, commercial, legal, warranty, and risk-allocation terms relating to the installation project.

DOVE COMMUNICATIONS, INC.

Printed Name: _____________________________________________

Title: _____________________________________________

Signature: _____________________________________________

Date: _____________________________________________

CLIENT:

Client Legal Name: _______________________________________________________

Printed Name: _____________________________________________

Title / Authority to Sign: _____________________________________________

Signature: _____________________________________________

Date: _____________________________________________

Copy of Contract Received (Date): _____________________________________________

For CSLB complaints: P.O. Box 26000, Sacramento, CA 95826 | (800) 321-CSLB | www.cslb.ca.gov